Defendant subcontracted with debtor for a security system installation project. Work delays and disruptions, although caused by the project owner, were ultimately the responsibility of the defendant, so it was liable to debtor for the additional costs
Date:
Tuesday, June 30, 1992
Judge:
Judge Timothy J. Mahoney (Retired)